Transform Your Space with Style

×

Privacy Policy

Last Updated: January 2026

Information We Collect

We collect information you provide directly to us, such as when you contact us through our website, request a consultation, or engage our services. This may include:

• Personal identification information (name, email address, phone number)
• Home address and property details
• Design preferences and project requirements
• Communication records and project documentation

How We Use Your Information

We use the information we collect to:

• Provide interior design and home decor services
• Communicate with you about your projects
• Send you updates and promotional materials (with consent)
• Improve our services and customer experience
• Comply with legal obligations

Information Sharing

We do not sell, trade, or rent your personal information to third parties. We may share your information only in the following circumstances:

• With trusted contractors and suppliers necessary for your project
• To comply with legal requirements or protect our rights
• With your explicit consent

Data Security

We implement appropriate security measures to protect your personal information against unauthorized access, alteration, disclosure, or destruction.

Your Rights

You have the right to access, update, or delete your personal information. Contact us at [email protected] to exercise these rights.

Contact Us

If you have questions about this Privacy Policy, please contact us at [email protected] or call +1 (213) 847-2094.

×

Terms of Service

Last Updated: January 2026

Acceptance of Terms

By engaging Home Decor Savants for interior design services, you agree to be bound by these Terms of Service. If you do not agree to these terms, please do not use our services.

Services Provided

Home Decor Savants provides interior design consultation, furniture selection, home makeover services, and related design services. All services are subject to availability and our professional assessment.

Client Responsibilities

• Provide accurate information about your space and requirements
• Allow reasonable access to the property for consultations and work
• Make timely payments according to agreed terms
• Communicate any concerns or changes promptly
• Respect our team members and contractors

Payment Terms

• Consultation fees are due at the time of service
• Project payments are typically structured as deposits and milestone payments
• All payments are due within 30 days of invoice date
• Late payments may incur additional charges

Project Timeline

Project timelines are estimates based on scope and complexity. Delays due to client changes, product availability, or unforeseen circumstances may extend completion dates.

Limitation of Liability

Home Decor Savants liability is limited to the amount paid for services. We are not responsible for indirect, consequential, or punitive damages.

Intellectual Property

Design concepts and plans remain the intellectual property of Home Decor Savants until full payment is received.

Contact Information

For questions about these terms, contact us at [email protected] or +1 (213) 847-2094.

×

Disclaimer

Last Updated: January 2026

Professional Services

Home Decor Savants provides interior design and home decor services based on our professional expertise and experience. Results may vary based on individual circumstances, property conditions, and client preferences.

No Warranty

While we strive for excellence in all our projects, we make no warranties or guarantees about:

• Specific aesthetic outcomes or personal satisfaction
• Compatibility with existing home systems or structures
• Long-term durability of recommended products
• Compliance with future building codes or regulations

Third-Party Products and Services

We may recommend third-party products, contractors, or services. We are not responsible for the quality, performance, or warranty of these third-party offerings.

Property Conditions

Our recommendations are based on visible conditions during consultations. We are not responsible for hidden structural issues, electrical problems, or other property defects that may affect design implementation.

Budget Estimates

Cost estimates are approximations based on current market conditions. Actual costs may vary due to product availability, labor rates, and project modifications.

Design Trends

Design recommendations reflect current trends and professional judgment. Style preferences and trends may change over time.

Client Decisions

Clients make final decisions on all design elements. We provide professional guidance but are not responsible for client choices that differ from our recommendations.

Limitation of Claims

Any claims must be made within 30 days of project completion. We reserve the right to assess and address concerns on a case-by-case basis.

Contact for Concerns

If you have concerns about our services, please contact us immediately at [email protected] or +1 (213) 847-2094.